Factors causing delays in the UAE construction industry amid the Covid-19 pandemic

Abstract

PurposeThis paper aims to measure the severity, frequency and importance of the factors causing delays in the United Arab Emirates (UAE) construction industry following the Covid-19 pandemic onset. The study also measures the likelihood of the effects caused by these delays.Design/methodology/approachA mixed approach of both qualitative and quantitative. Literature review was conducted to extract 40 factors of delays and 10 effects of delays. A survey was then administered to construction professionals in the UAE to collect the perceptions on the severity and frequency of factors of the causes of delays using a Likert Scale of 1–5 where 1 represented very low and 5 represented very high. Similarly, the respondents were also asked to rate the likelihood of the occurrence of the effects of the delays based on a Likert scale of 1–5 as well. Furthermore, Spearman’s rank correlation was also conducted to compute the level of agreement between the different parties; owner, consultants and contractors.FindingsThe results revealed that the top five factors of delays include: award the project for the lowest bidder, delay in progress payment, change orders by the owner, poor subcontractor performance and inadequate planning and scheduling by the contractor. The findings of this study emphasize the financial challenges and economic crisis brought upon the construction industry due to the pandemic. Furthermore, the pandemic also shifted the perceptions of construction professionals, who are now more aware of the delays caused by awarding the project to the lowest bidder who would not have the required qualifications to conduct efficient planning and scheduling that are relevant in the case of extraordinary events such as Covid-19. Moreover, a high level of agreement between the consultants and contractors was observed, with a Spearman’s rank correlation of 0.804. Additionally, the most likely effects of delays concluded from this study were time overrun/extension and poor quality of work.Originality/valueLiterature review is very rich in the field of construction projects delays. However, there is very limited research on the impact of Covid-19 in the context of construction projects delays, and insights from construction professionals regarding this matter are particularly lacking in literature. Therefore, this paper bridges the gap in literature by providing perceptions of construction professionals on the impact of Covid-19 on the factors causing delays in the UAE construction industry. The findings of this research are expected to be an invaluable resource for future to help the construction industry heal faster when encountering similar epidemics or extraordinary events.